Texas Roofing Contractor

Texas Roofing Contractor

HomeAll ArticlesContact

Terms and Conditions

These Terms and Conditions govern your use of our website, services, and any interactions with our Texas-based roofing contracting business. By accessing or using our website and services, you agree to abide by these Terms. If you do not agree with any part of these Terms, you should not use our services.

1. Definitions

  • "Client" refers to any person or entity that engages our roofing services.
  • "Services" include but are not limited to roofing installation, repair, inspection, and maintenance.
  • "Website" refers to
  • "Agreement" means these Terms and any related contracts entered into with the Client.

2. Scope of Services

We provide professional roofing services, including:

  • Residential and commercial roofing installations
  • Roof repairs and maintenance
  • Emergency roofing services
  • Inspections and consultations
  • Gutter and ventilation system work
  • Roof coatings and waterproofing
  • Storm damage repair and insurance claims assistance

All services are subject to availability and project-specific agreements. We aim to deliver high-quality workmanship and use industry-standard materials to ensure durability and customer satisfaction.

3. Quotes and Payments

  • Quotes provided are valid for 30 days from the date issued.
  • A signed contract and a deposit may be required before work commences.
  • Payment schedules will be outlined in the contract, typically structured in phases: deposit, progress payments, and final payment upon completion.
  • Late payments may incur additional fees, including interest charges.
  • We accept payments via credit card, bank transfer, checks, and other approved methods.
  • Failure to pay within the agreed timeframe may result in legal action or service termination.

4. Cancellations and Refunds

  • Clients must provide written notice for cancellations at least 7 days before the project start date.
  • Deposits may be non-refundable, subject to the contract terms and any costs incurred.
  • Refunds for incomplete work will be issued at our discretion based on the percentage of work completed.
  • If cancellation occurs after materials have been ordered, the client may be responsible for the cost of those materials.

5. Warranties and Guarantees

  • We offer limited warranties on materials and workmanship, as specified in your contract.
  • Manufacturer warranties on materials may vary, and it is the client’s responsibility to register for such warranties when required.
  • Warranty claims must be submitted in writing with proof of service, and we will inspect the issue to determine if it falls under our warranty policy.
  • Warranty coverage excludes damage due to natural disasters, lack of maintenance, or third-party interference.

6. Client Responsibilities

  • Ensure access to the worksite during agreed-upon hours.
  • Obtain necessary permits unless otherwise stated in the contract.
  • Remove or protect valuables inside and outside the property before work begins.
  • Inform us of any special conditions such as pets, children, or accessibility restrictions.
  • Maintain the roof properly after service completion and schedule regular inspections to extend its lifespan.

7. Liability and Indemnification

  • We are not liable for pre-existing damage or issues unrelated to our work.
  • Clients agree to indemnify us against claims resulting from misuse of our services, negligence, or third-party interference.
  • We are not responsible for damages caused by unforeseen events such as extreme weather conditions, vandalism, or acts of God.
  • Any claim against us must be submitted in writing within 30 days of the alleged incident.

8. Limitations of Liability

To the fullest extent permitted by Texas law, we are not responsible for:

  • Delays due to weather, supply chain issues, or unforeseen circumstances.
  • Indirect, incidental, or consequential damages, including lost profits or business disruptions.
  • Structural damages resulting from pre-existing conditions that were not visible during inspections.
  • Client negligence, including failure to maintain the roof or unauthorized modifications.

9. Termination of Services

We reserve the right to terminate services if:

  • The client breaches these Terms.
  • The project becomes unsafe or unfeasible.
  • Payment obligations are not met.
  • False information is provided regarding property conditions or permits.
  • Work conditions are hostile or unsafe for our crew.

10. Privacy Policy

Your use of our services is also governed by our Privacy Policy, available at [link to privacy policy]. We collect personal information to provide our services and do not share client data with unauthorized third parties.

11. Governing Law and Dispute Resolution

  • These Terms are governed by the laws of the State of Texas.
  • Disputes shall be resolved through mediation or arbitration before litigation.
  • Clients agree to notify us in writing of any disputes before taking legal action.
  • Litigation, if necessary, will be handled in the appropriate Texas court.

12. Worksite Conditions and Safety

  • Clients must ensure the worksite is free of hazards that could affect our crew’s safety.
  • We follow OSHA (Occupational Safety and Health Administration) regulations and industry standards.
  • If unsafe conditions arise, we reserve the right to pause work until the issue is resolved.
  • Clients are not permitted in the active work zone without prior approval.

13. Material Usage and Disposal

  • We use high-quality roofing materials sourced from reputable suppliers.
  • Leftover materials remain the property of the contractor unless otherwise agreed.
  • Disposal of old roofing materials will be handled per Texas environmental regulations.
  • Additional fees may apply for unexpected material disposal needs.

14. Emergency Repairs and Insurance Claims

  • We offer emergency roofing services for storm damage and unexpected leaks.
  • Clients should contact their insurance company before scheduling emergency repairs.
  • We assist with insurance claims but cannot guarantee claim approval or reimbursement.

15. Intellectual Property

  • All content on our website, including text, logos, images, and service descriptions, is protected by copyright law.
  • Clients may not use our branding or intellectual property without written permission.

16. Force Majeure

  • We are not responsible for delays or failures due to force majeure events, including natural disasters, labor strikes, pandemics, or government actions.

17. Amendments

We reserve the right to modify these Terms at any time. Updated Terms will be posted on our website and will take effect immediately upon publication.

18. Severability

  • If any part of these Terms is found to be unenforceable, the remaining provisions shall remain valid.

19. Entire Agreement

  • These Terms, along with any signed contracts, constitute the entire agreement between the client and us.
  • No verbal agreements or modifications are valid unless confirmed in writing.